Terms & Conditions

1. Definitions

• “Services” refers to website and app development, design, and related support provided by us.
• “Client” refers to any individual, business, or entity engaging our services.
• “Deliverables” refers to the final websites, apps, or other materials provided by us as part of the services.

2. Use of Services

• Our services are intended for lawful use only. You agree not to use our services for any illegal or unauthorized purpose.
• You are responsible for providing accurate project requirements and any materials (e.g., images, content) necessary for project completion.

3. Scope of Work

• We will provide services as outlined in the project agreement or proposal.
• Any changes to the project scope may result in additional fees or extended timelines.

4. Intellectual Property

5. Fees and Payment Terms

• Fees for services will be outlined in the project agreement.
• Payments must be made as per the agreed schedule.
• Late payments may incur penalties or interest.
• Refunds are not provided for completed milestones or deliverables.

6. Timelines and Delivery

• We will make reasonable efforts to meet project timelines. However, delays caused by the client (e.g., late approvals, incomplete information) may result in rescheduled delivery dates.
• We are not liable for delays caused by external factors beyond our control.

7. Confidentiality

• We will not disclose any confidential information provided by the client without written consent.
• Clients agree not to share our proprietary tools or methods with third parties without permission.

8. Liability and Indemnification

• We are not liable for any direct, indirect, or consequential damages resulting from the use of our deliverables.
• The client agrees to indemnify us against any claims arising from the content, data, or materials provided by the client.

9. Warranties and Disclaimer

• We warrant that our services will be performed professionally and to industry standards.
• We do not guarantee specific results, such as rankings, traffic, or user acquisition, unless explicitly stated in the project agreement.

10. Termination

• Either party may terminate the agreement with written notice.
• Upon termination, the client must pay for all completed work and any outstanding fees.
• We reserve the right to terminate the agreement if the client violates these terms or engages in unethical behavior.

11. Governing Law and Jurisdiction

• These terms are governed by the laws of India.
• Any disputes will be subject to the exclusive jurisdiction of the courts in Ludhiana.

12. Changes to Terms

We reserve the right to update these Terms and Conditions. Clients will be notified of significant changes.

13. Contact Us

For questions or concerns about these Terms and Conditions, contact us at:
Email: info@appvertix.com